Open RFP

PREQUAL - General Contractors: Larger Construction Projects $500,000 to $3,000,000: REOPENED YEAR 2 (Awarded OPEN QSR Submission Deadline for New Respondent November 2, 2026

Description: This Request for Supplier Qualifications (“RFSQ”) is an invitation by Centre d’excellence en approvisionnement FRANCOachat and its participating agencies (“CEA FRANCOachat”) to prospective respondents to qualify for eligibility to provide General Contractors for Larger Construction Projects between $500,000 to $3,000,000 for Conseil des écoles publiques de l’Est de l’Ontario as further described in Section A of the RFSQ Particulars (Appendix A) (the “Deliverables”). The Centre d’excellence en approvisionnement FRANCOachat (CEA FRANCOachat) is a shared service organization providing procurement services for member school boards in the province of Ontario. This competitive procurement process is being completed on behalf of the following school board: Conseil des écoles publiques de l’Est de l’Ontario 2445 Saint-Laurent Boulevard Ottawa (Ontario) K1C 6C3 This competitive procurement process ("Process") seeks to solicit prequalification proposals from qualified General Contractors interested in being placed on the Board’s Qualified Supplier Roster (QSR) list of contractors for construction projects in three separate categories listed in the table below. Category: - $500,000 to $3,000,000: This category applies to various larger budgeted projects including, but not limited to, renovation projects, larger repairs, demolitions, complex renovations and/or addition projects to both interior/exterior work in a portable classroom/school classroom/school site/daycare/administrative building. Projects with an estimated construction value of $3 million or more, will be published publicly. Only respondents on the Board’s QSR list will be invited to bid on the Board’s construction projects, unless otherwise allowed for in this document. The Procurement Restriction Policy The Procurement Restriction Policy is issued under the authority of the Management Board of Cabinet Act, 1990, and the Broader Public Sector Accountability Act, 2010. This Procurement Restriction Policy (the “Policy”) was established to restrict public sector buyers from procuring goods and services from U.S. businesses. The Policy was established as part of an Ontario government response to U.S. tariffs on Canadian products and services. If the relevant tariffs are removed, the Policy may be adjusted or rescinded. U.S. Business Definition “U.S. business” means a supplier, manufacturer, or distributor of any business structure (includes a sole proprietorship, partnership, corporation, or other business structure) that: 1. has its headquarters or main office located in the U.S., and 2. has fewer than 250 full-time employees in Canada at the time of the applicable procurement process. If a respondent or vendor is a subsidiary of another corporation, part 1 of the definition above is met if that respondent or vendor is controlled by a corporation that has its headquarters or main office located in the U.S. Please note that a respondent’s eligibility must be demonstrated before a Quotation may be accepted. A Quotation submitted by a U.S. business will be considered non-compliant and not evaluated if it does not satisfy the eligibility requirements set out in the procurement document(s).

Buyer: Conseil des écoles publiques de l'Est de l'Ontario
SchoolDistrict · ON, CA
Released: Dec 8, 2025
Closes: Nov 2, 2026(16 days left)

RFP documents

Solicitation files and supporting documents for this bid.

RFP documents aren’t available here yet.

Our team can help you find the original solicitation documents.

Request File Retrieval

Key Contacts on this RFP

Decision makers connected to this RFP from Conseil des écoles publiques de l'Est de l'Ontario.

Christian-Charles BouchardDirector of Education and Secretary-Treasurer

*******@************

+1 (***) ***-****

Danielle RyanDirector of Finance

*******@************

+1 (***) ***-****

Marie Chantal DesrosiersSuperintendent of Education

*******@************

+1 (***) ***-****

Similar active RFPs

Adjacent opportunities open for bidding right now.

Conseil des écoles publiques de l'Est de l'Ontario
School DistrictON
Posted
Dec 8, 2025
Closes
Nov 2, 2026
PREQUAL - Architectural Services - CEPEO REOPENED YEAR 2 (Awarded OPEN QSR Submission Deadline for New Respondents November 2, 2026)
This Request for Supplier Qualifications (“RFSQ”) is an invitation by Centre d’excellence en approvisionnement FRANCOachat and its participating agencies (“CEA FRANCOachat”) to prospective respondents to qualify for eligibility to provide Architectural Services for Conseil des écoles publiques de l’Est de l’Ontario as further described in Section A of the RFSQ Particulars (Appendix A) (the “Deliverables”). The Centre d’excellence en Approvisionnements FRANCOachat (CEA FRANCOachat) is a shared service organization providing procurement services for member school boards in the province of Ontario. This competitive procurement process is being completed on behalf of the following school board: Conseil des écoles publiques de l’Est de l’Ontario, 2445 St-Laurent Boulevard, Ottawa, ON K1G 6C3 The Board is seeking to qualify suppliers onto a roster of qualified suppliers (the “Qualified Supplier Roster (QSR)”) to perform various architectural services within all CEPEO’s regions and territory. Only firms on the Board’s QSR list will be invited to bid on the Board’s projects, unless otherwise allowed for in this document. Details regarding the QSR process and procedures are detailed in Appendix A – RFSQ Particulars – Deliverables. Respondents may select any category, should they have the ability to meet the Board’s requirements. The QSR list will be based on the following three (3) categories: Category 1 – Small and Medium Renovations ($100,000 to $1,449,999) Projects in this category are generally including but not limited to small and medium renovations (classroom/school/daycare), Category 2 – Major Renovation and/or Addition Projects ($1,500,000 to $5,999,999) Projects in this category are generally including but not limited to major renovations and/or addition construction projects (classroom/school/site/daycare) demolitions and/or retrofits. will have a single awarded zone. The single awarded zone covers the entire Board’s service area. Category 3 – New School Construction (Elementary, Secondary, K-12) (Greater than $6,000,000) Projects will have an estimated construction value greater than $6 million. Projects in this category are generally including but not limited to new school construction. Category 3 will have a single awarded zone. The single awarded zone covers the entire Board’s service area. The Procurement Restriction Policy The Procurement Restriction Policy is issued under the authority of the Management Board of Cabinet Act, 1990, and the Broader Public Sector Accountability Act, 2010. This Procurement Restriction Policy (the “Policy”) was established to restrict public sector buyers from procuring goods and services from U.S. businesses. The Policy was established as part of an Ontario government response to U.S. tariffs on Canadian products and services. If the relevant tariffs are removed, the Policy may be adjusted or rescinded. U.S. Business Definition “U.S. business” means a supplier, manufacturer, or distributor of any business structure (includes a sole proprietorship, partnership, corporation, or other business structure) that: 1. has its headquarters or main office located in the U.S., and 2. has fewer than 250 full-time employees in Canada at the time of the applicable procurement process. If a respondent or vendor is a subsidiary of another corporation, part 1 of the definition above is met if that respondent or vendor is controlled by a corporation that has its headquarters or main office located in the U.S. Please note that a respondent’s eligibility must be demonstrated before a Quotation may be accepted. A Quotation submitted by a U.S. business will be considered non-compliant and not evaluated if it does not satisfy the eligibility requirements set out in the procurement document(s).
Conseil des écoles publiques de l'Est de l'Ontario
School DistrictON
Posted
Dec 8, 2025
Closes
Nov 2, 2026
PREQUAL - Multiple Urban Services - CEPEO: REOPENED YEAR 2 (Awarded: OPEN QSR Submission Deadline for New Respondents November 2, 2026)
This Request for Supplier Qualifications (“RFSQ”) is an invitation by Centre d’excellence en approvisionnement FRANCOachat (“CEA FRANCOachat”) and its participating agencies to prospective respondents to qualify for eligibility to provide Multiple Urban Services for Conseil des écoles publiques de l’Est de l’Ontario as further described in Section A of the RFSQ Particulars (Appendix A) (the “Deliverables”). The Centre d’excellence en Approvisionnements FRANCOachat (CEA FRANCOachat) is a shared service organization providing procurement services for member school boards in the province of Ontario. This competitive procurement process is being completed on behalf of the following school boards: Conseil des écoles publiques de l’Est de l’Ontario, 2445 St-Laurent Boulevard, Ottawa, ON K1G 6C3 The Board is seeking to qualify suppliers onto a roster of qualified suppliers (the “Qualified Supplier Roster QSR”) to perform various services (noted below) with values not exceeding $99,999 at a variety of sites within all following regions: SERVICES 1. Urban Planner 2. Real Estate Appraiser 3. Land Surveyor 4. Inspection Engineer (Geotechnical and Environmental Assessments) REGIONS Ottawa and Surrounding Area Prescott – Russel Area Stormont Dundas & Glengarry Area Only respondents on the Board’s QSR list will be invited to bid on the Board’s projects, unless otherwise allowed for in this document. Respondents may select any service in one or more of the regions, should they have the ability to meet the Board’s requirements. The Procurement Restriction Policy The Procurement Restriction Policy is issued under the authority of the Management Board of Cabinet Act, 1990, and the Broader Public Sector Accountability Act, 2010. This Procurement Restriction Policy (the “Policy”) was established to restrict public sector buyers from procuring goods and services from U.S. businesses. The Policy was established as part of an Ontario government response to U.S. tariffs on Canadian products and services. If the relevant tariffs are removed, the Policy may be adjusted or rescinded. U.S. Business Definition “U.S. business” means a supplier, manufacturer, or distributor of any business structure (includes a sole proprietorship, partnership, corporation, or other business structure) that: 1. has its headquarters or main office located in the U.S., and 2. has fewer than 250 full-time employees in Canada at the time of the applicable procurement process. If a respondent or vendor is a subsidiary of another corporation, part 1 of the definition above is met if that respondent or vendor is controlled by a corporation that has its headquarters or main office located in the U.S. Please note that a respondent’s eligibility must be demonstrated before a Quotation may be accepted. A Quotation submitted by a U.S. business will be considered non-compliant and not evaluated if it does not satisfy the eligibility requirements set out in the procurement document(s).
Conseil des écoles publiques de l'Est de l'Ontario
School DistrictON
Posted
Dec 3, 2025
Closes
Nov 2, 2026
PREQUAL - Mechanical Contractors - All Zones (CS Viamonde & CSC Providence)(Awarded: OPEN VOR YEAR 3: Submission Deadline for New Respondents November 2, 2026 by 2 PM Local Time)
This Request for Supplier Qualifications (“RFSQ”) is an invitation by Centre d’excellence en approvisionnement FRANCOachat and its participating agencies (“CEA FRANCOachat”) to prospective respondents to qualify for eligibility to provide Mechanical Work Contractors for Conseil scolaire Viamonde and Conseil scolaire catholique Providence as further described in Section A of the RFSQ Particulars (Appendix A) (the “Deliverables”). The Centre d’excellence en approvisionnement FRANCOachat (CEA FRANCOachat) is a shared service organization providing procurement services for member school boards in the province of Ontario. This competitive procurement process is being completed on behalf of the following school boards: 1. Conseil scolaire Viamonde 1 Vanier drive, Suite 101 Welland (Ontario) L3B 1A1 2. Conseil scolaire catholique Providence 7515 Forest Glade drive, Windsor (Ontario) N8T 3P5 This competitive procurement process ("Process") seeks to solicit prequalification proposals from qualified Mechanical Contractors interested in being placed on the Board’s Vendor of Record (VOR) list of contractors for construction projects valued between $100,000 to $1,500,000 within the zones listed in the table below. Respondents may select to be prequalified for one or more zones. # ZONES 1 Chatham-Kent, Windsor-Essex, (CS Viamonde & CSC Providence) 2 Hamilton, Niagara, Waterloo, Wellington (CS Viamonde ONLY) 3 Kawarthas, Simcoe (CS Viamonde ONLY) 4 London-Middlesex, Oxford, Lambton, Bruce-Grey (CS Viamonde & CSC Providence) 5 GTA: Dufferin, Peel, Halton, Toronto, Durham, York, Orangeville, Bowmanville (CS Viamonde ONLY) Only contractors on the Board’s VOR list will be invited to bid on the Board’s construction projects. The Procurement Restriction Policy The Procurement Restriction Policy is issued under the authority of the Management Board of Cabinet Act, 1990, and the Broader Public Sector Accountability Act, 2010. This Procurement Restriction Policy (the “Policy”) was established to restrict public sector buyers from procuring goods and services from U.S. businesses. The Policy was established as part of an Ontario government response to U.S. tariffs on Canadian products and services. If the relevant tariffs are removed, the Policy may be adjusted or rescinded. U.S. Business Definition “U.S. business” means a supplier, manufacturer, or distributor of any business structure (includes a sole proprietorship, partnership, corporation, or other business structure) that: 1. has its headquarters or main office located in the U.S., and 2. has fewer than 250 full-time employees in Canada at the time of the applicable procurement process. If a respondent or vendor is a subsidiary of another corporation, part 1 of the definition above is met if that respondent or vendor is controlled by a corporation that has its headquarters or main office located in the U.S. Please note that a respondent’s eligibility must be demonstrated before a Quotation may be accepted. A Quotation submitted by a U.S. business will be considered non-compliant and not evaluated if it does not satisfy the eligibility requirements set out in the procurement document(s).
Conseil des écoles publiques de l'Est de l'Ontario
School DistrictON
Posted
Dec 3, 2025
Closes
Nov 2, 2026
PREQUAL - Civil Contractors - All Zones (CS Viamonde & CSC Providence) (Awarded: OPEN VOR YEAR 3 : Submission Deadline for New Respondents November 2, 2026 by 2 PM Local Time) Local Time)
This Request for Supplier Qualifications (“RFSQ”) is an invitation by Centre d’excellence en approvisionnement FRANCOachat and its participating agencies (“CEA FRANCOachat”) to prospective respondents to qualify for eligibility to provide Civil Work Contractors for Conseil scolaire Viamonde and Conseil scolaire catholique Providence as further described in Section A of the RFSQ Particulars (Appendix A) (the “Deliverables”). The Centre d’excellence en approvisionnement FRANCOachat (CEA FRANCOachat) is a shared service organization providing procurement services for member school boards in the province of Ontario. This competitive procurement process is being completed on behalf of the following school boards: 1. Conseil scolaire Viamonde 1 Vanier drive, Suite 101 Welland (Ontario) L3B 1A1 2. Conseil scolaire catholique Providence 7515 Forest Glade drive, Windsor (Ontario) N8T 3P5 This competitive procurement process ("Process") seeks to solicit prequalification proposals from qualified Civil Work Contractors interested in being placed on the Board’s Vendor of Record (VOR) list of contractors for construction projects valued between $100,000 to $1,500,000 within the zones listed in the table below. Respondents may select to be prequalified for one or more zones. # ZONES 1 Chatham-Kent, Windsor-Essex, (CS Viamonde & CSC Providence) 2 Hamilton, Niagara, Waterloo, Wellington (CS Viamonde ONLY) 3 Kawarthas, Simcoe (CS Viamonde ONLY) 4 London-Middlesex, Oxford, Lambton, Bruce-Grey (CS Viamonde & CSC Providence) 5 GTA: Dufferin, Peel, Halton, Toronto, Durham, York, Orangeville, Bowmanville (CS Viamonde ONLY) Only contractors on the Board’s VOR list will be invited to bid on the Board’s construction projects. The Procurement Restriction Policy The Procurement Restriction Policy is issued under the authority of the Management Board of Cabinet Act, 1990, and the Broader Public Sector Accountability Act, 2010. This Procurement Restriction Policy (the “Policy”) was established to restrict public sector buyers from procuring goods and services from U.S. businesses. The Policy was established as part of an Ontario government response to U.S. tariffs on Canadian products and services. If the relevant tariffs are removed, the Policy may be adjusted or rescinded. U.S. Business Definition “U.S. business” means a supplier, manufacturer, or distributor of any business structure (includes a sole proprietorship, partnership, corporation, or other business structure) that: 1. has its headquarters or main office located in the U.S., and 2. has fewer than 250 full-time employees in Canada at the time of the applicable procurement process. If a respondent or vendor is a subsidiary of another corporation, part 1 of the definition above is met if that respondent or vendor is controlled by a corporation that has its headquarters or main office located in the U.S. Please note that a respondent’s eligibility must be demonstrated before a Quotation may be accepted. A Quotation submitted by a U.S. business will be considered non-compliant and not evaluated if it does not satisfy the eligibility requirements set out in the procurement document(s).

See your top accountsScan your site in seconds. Starbridge identifies your ICP and surfaces emerging opportunities from board meetings, job changes, new grants, contract expirations, RFPs, and more.

See your top 10 accounts

Conseil des écoles publiques de l'Est de l'Ontario

School DistrictON

Posted

Dec 8, 2025

Closes

Nov 2, 2026

PREQUAL - Architectural Services - CEPEO REOPENED YEAR 2 (Awarded OPEN QSR Submission Deadline for New Respondents November 2, 2026)

This Request for Supplier Qualifications (“RFSQ”) is an invitation by Centre d’excellence en approvisionnement FRANCOachat and its participating agencies (“CEA FRANCOachat”) to prospective respondents to qualify for eligibility to provide Architectural Services for Conseil des écoles publiques de l’Est de l’Ontario as further described in Section A of the RFSQ Particulars (Appendix A) (the “Deliverables”). The Centre d’excellence en Approvisionnements FRANCOachat (CEA FRANCOachat) is a shared service organization providing procurement services for member school boards in the province of Ontario. This competitive procurement process is being completed on behalf of the following school board: Conseil des écoles publiques de l’Est de l’Ontario, 2445 St-Laurent Boulevard, Ottawa, ON K1G 6C3 The Board is seeking to qualify suppliers onto a roster of qualified suppliers (the “Qualified Supplier Roster (QSR)”) to perform various architectural services within all CEPEO’s regions and territory. Only firms on the Board’s QSR list will be invited to bid on the Board’s projects, unless otherwise allowed for in this document. Details regarding the QSR process and procedures are detailed in Appendix A – RFSQ Particulars – Deliverables. Respondents may select any category, should they have the ability to meet the Board’s requirements. The QSR list will be based on the following three (3) categories: Category 1 – Small and Medium Renovations ($100,000 to $1,449,999) Projects in this category are generally including but not limited to small and medium renovations (classroom/school/daycare), Category 2 – Major Renovation and/or Addition Projects ($1,500,000 to $5,999,999) Projects in this category are generally including but not limited to major renovations and/or addition construction projects (classroom/school/site/daycare) demolitions and/or retrofits. will have a single awarded zone. The single awarded zone covers the entire Board’s service area. Category 3 – New School Construction (Elementary, Secondary, K-12) (Greater than $6,000,000) Projects will have an estimated construction value greater than $6 million. Projects in this category are generally including but not limited to new school construction. Category 3 will have a single awarded zone. The single awarded zone covers the entire Board’s service area. The Procurement Restriction Policy The Procurement Restriction Policy is issued under the authority of the Management Board of Cabinet Act, 1990, and the Broader Public Sector Accountability Act, 2010. This Procurement Restriction Policy (the “Policy”) was established to restrict public sector buyers from procuring goods and services from U.S. businesses. The Policy was established as part of an Ontario government response to U.S. tariffs on Canadian products and services. If the relevant tariffs are removed, the Policy may be adjusted or rescinded. U.S. Business Definition “U.S. business” means a supplier, manufacturer, or distributor of any business structure (includes a sole proprietorship, partnership, corporation, or other business structure) that: 1. has its headquarters or main office located in the U.S., and 2. has fewer than 250 full-time employees in Canada at the time of the applicable procurement process. If a respondent or vendor is a subsidiary of another corporation, part 1 of the definition above is met if that respondent or vendor is controlled by a corporation that has its headquarters or main office located in the U.S. Please note that a respondent’s eligibility must be demonstrated before a Quotation may be accepted. A Quotation submitted by a U.S. business will be considered non-compliant and not evaluated if it does not satisfy the eligibility requirements set out in the procurement document(s).